📄 CONTRACT GENERATOR

Nepal-Standard Construction Contract

Fill in the details below to generate a printable agreement

Contract Type

Party A (Client / Employer)

Name

Address

PAN/Citizenship No.

Party B (Contractor / Vendor)

Name

Address

PAN/VAT No.

Project Details

Project Title

Location

Contract Amount (Rs.)

Start Date

Expected Completion

Terms & Conditions

Full Construction Agreement

Executed under the laws of Nepal — Dated July 15, 2026

This Agreement is made between [Party A Name] of [Party A Address] ("Party A / Client"), and [Party B Name] of [Party B Address] ("Party B / Contractor").

1. Project

Project: [Project Title]
Location: [Location]
Contract Value: Rs. [Amount]
Start Date: [Start Date] — Expected Completion: [Completion Date]

2. Terms & Conditions

1. Payment: 20% advance, 60% on milestone completion, 20% on final handover. 2. Warranty: 1 year defects liability period from handover date. 3. Delay penalty: 0.1% of contract value per day of delay beyond agreed completion date, capped at 10%. 4. Force majeure: Neither party liable for delays caused by natural disaster, strike, or government restriction. 5. Dispute resolution: Any dispute to be settled through mediation in Nepal, failing which as per Nepal's Arbitration Act.

Signature — Party A

[Party A Name]

Signature — Party B

[Party B Name]

← Back to Quote Generator

This generates a standard working draft only — have it reviewed by a licensed advocate before signing for high-value contracts.